Machinery (General / Rotated) Expert Witnesses: 23

Peter J. Sullivan is a World Class Certified ASE Technician and ASE Certified Master Technician in Heavy Duty Truck, Passenger Car / Light Truck, Collision Repair, and Machinist, (National Institute for Automotive Service Excellence). He has over 35 years of technical, academic, operational, and managerial experience in the private and commercial transportation, heavy equipment, marine, and recreational vehicle industries.

Mr. Sullivan has extensive experience performing vehicle inspections and downloads of event data recorders and electronically stored information (ESI), including analysis, validation, testing, and preservation on almost all makes and models of vehicles and equipment.

Litigation Support - Mr. Sullivan utilizes his comprehensive legal, technical, and FMCSA / DOT knowledge to specialize in:

Product Defect Cases Driver or Motor Carrier Compliance Electronic Engine Control (ECM) Electronic Throttle Control Electronic Power Steering

Anti-Lock Brake Supplemental Restraint Computerized Systems Closed-loop Systems Hydraulics

He and his team perform accident site and vehicle inspections, perform data downloads, including analysis, on most all makes and models of vehicles and equipment, reconstruct accidents, perform exemplar and product testing, metallurgical testing, fluid analysis, and CMV driver and motor carrier compliance analysis. His primary areas of expertise include medium duty / heavy duty truck, hy-rail, light duty car / truck, motorcycle, ATV, marine, heavy equipment, machinery, tire, bicycle, commercial motor carrier safety and DOT compliance, and commercial motor vehicle driver / operator qualification and compliance, and job site safety.

Mr. Sullivan's services are available to counsel representing both Plaintiff and Defense. His litigation support services also include expert reports, depositions, and testimony for trial, OSHA, and governmental hearings.

View Peter Sullivan's Consulting Profile.

Dr. Adam K. Aleksander, PhD, PE, CSP, has over 40 years of experience in the areas of Mechanical Engineering, Human Factors, and Safety Engineering. He combines both academic credentials and active work in industry to provide a grounded perspective in Product Liability, Industrial Incidents, Warnings, and OSHA related issues. He is also a VP of an Energy Services firm, with over 35 overseas assignments related to forensic services, power utility issues, and equipment failures.

Dr. Aleksander has been a practicing engineer since 1972, focusing his Manufacturing, Consulting and Forensic investigations on Problem Definition and Root Cause Analysis of complex problems in confidential issues. His firm has experience encompassing an enormous variety of claims, from large $45 million dollar dam claims, to environmental clean-up claims, to small road construction claims. His litigation services often involve reconstruction, perception reaction studies, warnings, equipment operation, mechanical failures, industrial accidents, skiing, and bicycling injuries.

As an Expert Witness, Dr. Aleksander has worked with many clients, including plaintiff's and defendant's attorneys, both civil and criminal, attorneys representing corporations, corporations in the power utility area, and corporations that produce products. His services are also available to insurance executives with complex claims issues that involve industrial or utility related losses. Dr. Aleksander has been retained over 125 times in a wide range of technical investigations.

Litigation Expertise:

• Product Liability - Design, Manufacturing and Marketing Defects, Involving Damage, Injury or Fatality
• Equipment Failures - Proximal Cause of Failure with Contributing Factors
• Human Factors, Visibility, Ergonomics, and General Research Issues - Product Usability, Warnings, Instructions, Perception, Reaction Time, Visibility and Conspicuity Issues
• Construction, OSHA, and Safety Engineering - Regulatory and Safety Issues
• Industrial Projects
• Power Utility - Service and Equipment Failures

View Dr. Aleksander's Consulting Profile.

David Smith is an experienced mechanical engineer (MS, PE) with seven issued patents. Award-winning inventor. Vice President of Alpine Engineering and Design, a mechanical engineering consulting company with clients around the United States ranging from individual inventors to Fortune 500 companies. Worked on the development of multiple successful products including among other things: aerial lifts, garbage trucks, thrill rides, ziplines, trailers, oil and gas equipment, exercise equipment, manufacturing equipment, and multiple consumer products. 

Graduated Cum Laude with a bachelor's degree in mechanical engineering. Completed a master's of science degree in mechanical engineering and an MBA with an emphasis in product development. Licensed professional engineer (PE) and certified safety professional in comprehensive practice (CSP). Certified trainer for boom lifts, scissor lifts, rough terrain, and counterbalanced forklifts. Over 10 years of experience in product development, patents, equipment safety, and risk assessments. 

Experienced expert witness having drafted over 200 reports/declarations in patent cases and catastrophic injury and death cases. Designed and built multiple custom testing devices to obtain data and evaluate opinions. Created multiple demonstratives to explain the mechanics and circumstances of accident sequences and patented devices. Testified in deposition 11 times and in trial once.

Expert Witness Services Professional Expert Reports Testing Forensic/Failure Analysis Accident Reconstruction Demonstratives Inspections/Measurements Compliance with Standards Expert Testimony Patent & Patent Related Issues Patent Searches Provisional Patent Complete with Illustrations Patent Infringement Review

Product Development Innovative Concept Multi-Industry Experience Powerful Design Tools Full Service Fabricating Materials Design Analysis Finite Element Analysis (FEA) Hydraulics, Pneumatics, Electrical Structural Integrity Tests Value Analysis

Thomas Barth has a foundation of 47 years as a Crane Operator, Crane Inspector, and Crane Operator Trainer, approved by the U.S. Department of Labor.

As a crane operator and crane inspector, Mr. Barth has proven his professionalism as an expert witness in crane accident investigations across the country. His career-long commitment to crane safety has led him to carefully study the industry's practices, procedures and equipment.


Experience:

• Water - Mr. Barth has 13 years of experience working cranes on the water, including off loading barges, jack-up platforms, general cargo and construction materials, pile driving, clamming and hook work


• Land - His operator experience on land includes working in Prudhoe Bay oilfield, setting steel, tilt ups, building trades, heavy picks, drag lining, and using multiple cranes to make various heavy picks

Litigation Support - Mr. Barth has over 15 years of experience as a crane accident investigator and expert witness. He has investigated more than 55 high-profile crane accidents.

Piers Morgan interview with Thomas Barth on CNN News

Mr. Barth's experience with a wide variety of cranes in diverse industries and locations has been invaluable to attorneys and legal teams in need of a professional evaluation. He has a keen understanding of the underlying principles and potential causes in accident scenarios. Mr. Barth also knows how to evaluate accident reports from government agencies, witness depositions, inspection reports, lift plans, and other evidence. He is an excellent communicator with the ability to clearly express his answers, and the reasons for them, during video or written depositions, or in the courtroom.

Types Of Cranes:

• Cranes - Crawlers, Trucks, Hydraulics, Pedestals, Overheads, Hoists, Lifts
• Construction & Farm Machinery
• Industrial Equipment & Machinery

View Thomas Barth's Consulting Profile.

Carl Berkowitz, PE, Ph.D., AICP, is a Transportation and Traffic Engineering expert with almost 50 years of expertise. He's held various managerial and administrative positions in the transportation industry, government, private, and academic sectors.

Dr. Berkowitz has extensive multi-modal experience in planning, design, engineering, safety, security, construction, maintenance, operations, and management. He has written and edited numerous reports, studies, articles, and columns for major publications, journals, newspapers and scholarly periodicals.

Background Experience:

• Transportation and Traffic Engineering Consultant, 1988 - Present
• New York City Department of Transportation, New York, 1970 – 88
• New York State Office of Planning Coordination, New York, 1967 - 70
• New York State Department of Transportation, Babylon, NY, 1963 - 67
• New York City Transit Authority, New York, 1962 - 63

Litigation Support - Dr. Berkowitz has served as a litigation consultant since 1997.  He has the background and experience to make him ideally suited to contribute important information at every stage in the litigation process. Dr. Berkowitz is able to explain complex issues in layman terms, suggest strategies, investigate and uncover facts, perform literature reviews, research, and prepare safety evaluations. He has been deposed / testified over 50 times in the last 5 years.

Accident Investigation & Reconstruction Slip Trip & Fall Pedestrian & Bicycle Safety Railroad Safety Bus & Truck Safety Biomechanics & Human Factors Student Safety FELA & OSHA Accessibility / ADA Parking Lots & Garages

Construction Safety Elevators & Escalators Equipment & Machinery Traffic Engineering Traffic Lighting / Visibility Transportation Engineering Transportation Safety Transportation Rules & Regulations Terminals Walking & Working Surfaces

Cory W. Bruner has 28 years of experience in Safety in Construction and General Industry. Mr. Bruner is a qualified Safety Professional and holds a Safety Management Practitioner Certification. He has 25 years of Safety, Health and Environmental experience and 15 years specializing in Electrical and  Concrete Pumping. Mr. Bruner has provided services to clients in the Concrete Pumping, General, Construction, Electrical, Oil and Gas, Legal, and Insurance Industries. 

Concurrently with Bruner Safety Consulting, Mr. Bruner serves as Corporate Director of Risk Management, Safety and HR at Facility Solutions Group, Inc.  In this role, he oversees all aspects of Safety and Health including but not limited to policy and development, implementation, training, pre-qualification coordination, injury prevention investigation and reporting, site loss control auditing, management of facility safety trainers and staff, safety, and safety budgeting. 

Litigation Support - Mr. Bruner has provided expert opinions in numerous state and federal accident and injury cases. He specializes in electrical, concrete pumping accidents, and fatalities in construction, oil and gas, chemical process, and systems industry accidents and fatalities. Mr. Bruner is experienced with Federal and numerous State DOT / FMCSA regulatory compliance matters. He provides root cause analysis with corrective measures. 

Areas of Expertise:

Concrete Pumping Accidents Work Place Accidents Fall Accidents Roof Fall Accident, / Fatality Ladder / Scaffold Accidents Crane Accident Energized Electrical Accidents Power Line Accidents Pinch Point Accidents Lockout Tagout Concrete Pumping Injury OSHA Safety

Workplace Amputation Heavy Equipment Accident Blast Drill Rig Accident Power Tool Accident Power Tool Fatality Oil and Gas Safety Ammonia Refrigeration Accidents Commercial Vehicle Accident Parking Lot Trip / Fall Chemical Accidents Workplace Ergonomics Meat Packing Accidents

View Bruner Safety Consulting's Consultant Profile.

Thomas H. Burtness, PE, is an Electrical Engineer specializing in both Electrical and Building Construction - equipment selection, specification, and installation (actually “working with the tools”), as well as cost control techniques.

Background - Mr. Burtness has 40+ years of experience in the design, specification, construction contract administration, installation, startup, and troubleshooting of electrical power, on-site generation, distribution, control, and instrumentation systems and equipment for residential, commercial, industrial, and municipal occupancies. His experience also includes water, wastewater, and stormwater treatment plants, and military facilities.

Additional expertise includes Illumination Engineering for street, roadway, and area lighting including photometric footcandle requirements, calculations, field verification, equipment specifications, installation, and analysis of failure, glare, overlighting and underlighting.

Litigation Support - Since, 1981, Mr. Burtness has been providing forensic electrical engineering services to insurance companies and attorneys including accident and failure investigations, determination of cause and origin, litigation support, expert opinions, reports, and testimony. His services are available nationwide, with PE registration by comity available in most states.

Cases Involve:

Industrial Accidents Electrocution Personal Injury Fire Equipment and Machinery Failure

Failure of Safety Circuitry Grounding Lightning Damage and Fire Construction Defects / Contract Claims Design and Specification Disputes

View Thomas Burtness' Consulting Profile.

Michael A. Pollock, PE, USPTO, is a Mechanical Engineer responsible for the design and engineering of commercial, industrial, manufacturing, institutional, and residential venues, as well as efforts relating to services and products used in and around these facilities. Mr. Pollock's full CV can be viewed at cogentexpert.com.

Business and industries include electronics, safety and construction, building materials, polymers and plastics, instrumentation manufacturing, petrochemicals, chemicals, pharmaceuticals, colleges, athletic facilities, textiles, coatings and resins, food storage, biosciences, supermarkets, inks & pigments, automotive, facility and real estate operations, agricultural, transportation, nuclear, healthcare, nutrition, retail, distributors, pulp and paper, packaging, utilities, apparel, and R&D centers.

Litigation Support - Mr. Pollock is a subject matter expert in Commercial and Industrial Engineering Applications and Projects, as well as engineering standards and applicable codes (ASHRAE, ASME, NIST, NFPA, NBIC, ASTM, SAE, LEED, ASCE, GMP, ISA, BOCA, and EPA Regulations.) He has engaged with local, state, and governmental officials and agencies regarding numerous matters over his commensurate years of experience.

Areas of Expertise:

Investment Engineering Economics Mechanical Engineering Standard of Care Architectural Standard of Care Construction Delay Construction Defect Construction Schedule Analysis Accident Analysis Metallurgical Failure Rotating Equipment Electrical Failure Chemical Failure Processes Instrumentation and Controls

Chillers Coatings Refrigeration Thermodynamics Water Treatment Steam Systems and Boilers   Power and Utilities Energy Conservation Environmental Impact Safety HVAC Project Management Product Development

Registrations

• Professional Engineer: PA (PE075410)
• American Bar Association (ABA) – Construction Forum
• Environmental Protection Agency (EPA) Clean Air Act Certification – Universal (includes Chillers, HVAC & Refrigeration)
• United States Patent & Trademark Office Registered (USPTO)                              

Forensic Consulting Experience

Warehouse Distribution Facility – Maryland - Evaluated a $10M (million) claim relating to purported construction defect claims by the 600,000 sq. ft. facility owner against the facility construction contractor and an original equipment manufacturer relating to installed infrastructure in the facility. Developed an expert opinion and expert report regarding the analysis of the purported defects and a proposed repair solution to correct said defects. 

 Psychiatric Hospital Facility – North Carolina – Evaluated a $28M (million) construction claim by the general contractor against a hospital facility concerning a $100M facility construction project.  Developed an expert opinion and report for general construction issues, constructability, design revisions, and corresponding delay analysis for mechanical, HVAC, electrical, smoke and fire, structural, security and building automation systems. 

Forensics Consulting Work-in-Progress 

• 2022 – International Trade Commission (ITC) Matter – Resin Manufacturing Facility Construction Delay / Completeness Analysis
• 2022 – Mechanical Systems Coatings Matter Analysis
• 2021 – Industrial Manufacturing Facility Standard of Care Matter, Construction Defect, Construction Delay     
• 2021 – Electrical Distribution System Construction Defect Matter, Standard of Care
• 2021 – Hotel Facility HVAC Materials of Construction Related Defect Matter

Envista Forensics is a global leader in Forensic Engineering & Recovery Solutions. They provide Cause & Origin, Failure Analysis, Fire and Explosion Investigations, Accident Reconstruction, Damage Evaluations and Equipment Restoration Services following disasters of all kinds. Envista has offered Consulting Services to the insurance, legal and risk management industries, as well as businesses, public entities, and universities for over 25 years.

Their Experts travel globally from 30 offices located across the U.S., Canada, Mexico, the U.K., Australia and Singapore. Envista's experience counts when equipment, systems, structures, or data have been threatened by catastrophe or litigation. Their experts and advisors determine cause and responsibility, and identify the nature and extent of damage or loss and provide a full range of solutions to protect their assets.

Envista's technical professionals are trusted advisors and industry leaders. Their expertise is broad and deep, capable of withstanding all forms of scrutiny. Envista's services are available globally so that certainty is assured no matter where in the world it is needed. As the recovery from disasters has grown more complex, Envista has developed a comprehensive array of services to help their clients and has associates located around the globe to provide assurance no matter the type of loss or location of the disaster. Envista helps attorneys quickly get to meaningful answers on the many technical issues at the center of a dispute. Their engineers have decades of experience working with both defendants and plaintiffs.

They offer effective Expert Witness Testimony, with the ability to communicate effectively, build rapport with juries and judges, and maintain adherence to structured, methodical approaches in drawing conclusions are all extremely critical. Envista Forensics understands how critical the selection of an expert can be, and we understand what makes experts effective. Their court qualified experts have extensive experience providing expert testimony on a wide variety of engineering and technical matters.

Areas of Expertise:

Aviation & Aerospace Biomechanics Construction Defects Digital Forensics Electrical Injury & Electrocutions Causation Chemical Computer / Network Equipment Failure Construction Defect Disputes over Reparability of Damage Electrical Failure Equipment Restoration Fire & Explosion Analysis Equipment Restoration

Industrial / Manufacturing Equipment Materials Failure Mechanical Accidents Mechanical Failure Medical / Laboratory Equipment Product Failure / Liability Project Management Structural Failure Subrogation Utility & Energy Valuation of Structures or Equipment Vehicle Accident Investigation Workplace / Premises Accidents

View Envista's Consulting Profile.

Eugene R. Camerota is a Professional Consulting Engineer. His consulting experience includes the analytical and experimental studies of Engineering problems dealing with Accident Reconstruction and Product Liability. His work includes the following specialties:

Automotive / Motorcycle Accident Reconstruction

Crash Data Retrieval

Seat Belt Restraint Analysis

Automotive Component Design Evaluation

Construction Equipment

Industrial / Portable Machinery

Consumer Product Evaluation

OSHA

Slip and Fall

Dr. Kevin A. Rider, PhD, PE, CPE of Forensic Human Factors, LLC., providing investigations and expert testimony regarding predictable human behavior, particularly as it relates to motor vehicle and pedestrian collisions, premises liability, and slips, trips and falls, the design and use of products, and adequacy of warnings/instructions. His work focuses on identifying the Human Factors Elements that lead to unfortunate incidents, and what should have been done to prevent them. 

Dr. Rider is a Licensed Professional Engineer and Certified Professional Ergonomist, and has studied human movements and behavior, and served as a human factors consultant since 1999, including five years teaching industrial engineering and occupational safety courses at West Virginia University. He has presented at professional conferences, both nationally and abroad, and his research is published and cited in a number of peer-reviewed journals. He continues to serve as a reviewer for conference and journal manuscripts. 

Dr. Rider has testified over 100 times, and excels at educating attorneys and jurors. His services are available to attorneys for both Plaintiff and Defense. 

Areas of Expertise:

• Driver Behavior - Cell Phone Use and other In-Vehicle Distractions
• Product Liability - Design, Guards, Warnings, Adequacy of Instructions
• Premises Liability - Sidewalks, Shopping Centers, Community Parks, Retail Displays
• Slips, Trips, and Falls
• Visibility and Lighting - Illumination and Conspicuity of Objects
• Workplace Safety - Defective Products, Gross Negligence or Misconduct, Third Party Actions on Worksites
• Machine Guarding 

.

The four PhD and registered PEs at Miller Engineering are celebrating 40 years of Professorships at three universities along with providing services to Government, Insurance, and Industry—through research, publications, presentations, and expert testimony. We have a dedicated office with a full time staff of engineers, researchers, and technical writers. The span of our collective academic and experiential expertise covers well the Mechanical, Electrical, Chemical, Agricultural, Industrial, Human Factors, Ergonomic and Safety fields of engineering. The areas listed below are from actual projects completed in our 40 years of history. 

Vehicles Car/Truck Accident Reconstruction Crash Data Retrieval (CDR) Visibility & Reaction Time Analysis Tires, Trailers, Brakes & Accelerators Truck/Off Road Vehicle Egress/Ingress Traffic Signing and Construction Zones Electronic Vehicles Mechanical & Electrical Safety Product Safety & Analysis Machinery - Metal, Wood, Plastic Molding Machine Guarding & Safety, Robots, Automation Hazard and Risk Analysis Employee Safety Procedures – OSHA Electrical Distribution & Transmission Hazards

Warnings & Instructions Warning Labels & User Manual Design Hazard Analysis & Product Label Designs Medical Device & Drug Warnings & Instructions Inadequate Warnings Analysis Standard Compliance (ANSI Z535) Product Recall Information & Strategies Consumers/Household Safety Appliances & Tools Child Furniture, Choking, Playgrounds Swimming Pools & Exercise Equipment Recreation - ATV, Boats, Bicycles, Boards Ladder, Stair, Step and Railing Accidents Slip, Trip, & Fall Accidents CPSC Recall Information & Strategies

Chemicals Safety & Labeling NEW OSHA HAZCOM (2012) & GHS Review MSDS, SDS and Product Label Compliance Toxic Torts - Diacetyl, Asbestos, Benzene, Lead, Carbon Monoxide Vaping & E-Cigarette Health Effects Chemical Exposures & Workplace Safety Chemical Inhalation, Ingestion, Dermal Contact Contamination - Water & Environmental Manufacturing & Process Line Accidents Slips, Trips, Falls, & Entanglements Fires & Explosions Cause & Origin Investigations Gas, Vapor, & Electrical Spontaneous Combustion Vaping & E-cigarette Battery Failures Fire Control & Explosion Issues

Agriculture Tractor & Equipment Accidents Chemical Applications & Exposures Crop Storage & Harvesting Accidents Pesticides Construction Vehicle Visibility Accidents Slip, Trip, & Fall Accidents Power Tool Repetitive & Immediate Injuries Scaffolding - Cranes - Hoisting - Fork Lifts Insurance Subrogation & Forensics Accident Investigations Electrical & Fire Causation Chemical Leakage Damage Defective Equipment Injuries Premise and Process Damages

James M. Miller, PE, PhD – Founder  Dr. Miller is an Emeritus Engineering Professor at the University of Michigan. He has directly served in Washington originating several Federal OSHA safety regulations, and interacts regularly with CPSC regarding safety and product recalls. Dr. Miller often works on projects relating to compliance with occupational safety standards, provides upper management guidance on product design, recall and liability issues, and serves as an expert witness.

Mark R. Lehto, PhD – Co-Founder Dr. Lehto is a Professor of Engineering at Purdue University. He completed his Ph.D. in engineering at the University of Michigan, where he specialized in Human Factors Engineering, in particular Warnings and Labeling. Dr. Lehto specializes in knowledge engineering, warnings and instructions, structuring expert systems, accident modeling, accident statistical analysis, consumer product safety, boating safety, in-field national surveys of product usage, and product information effectiveness.

David R. Clark, PE, PhD – Co-Founder Dr. Clark is an Emeritus Engineering Professor at Kettering University. He was an engineering PhD graduate from the University of Michigan, where he specialized in human factors engineering and system safety analyses. He has a special expertise in electrical fire- and explosion-related accidents, and has extensive experience working for loss control companies, performing over 150 fire origin and cause investigations in the past few years.

Adam M. Olshove, PE, MSE – Engineering Manager Mr. Olshove has over 10 years of experience providing consulting services to industry and the legal profession. He holds an MS in Mechanical Engineering with a focus on control systems and battery modeling (2019), and a BS in Mechanical Engineering (2012), both from the University of Michigan. He has performed dozens of on-site investigations nationwide in relation to consumer product design and industrial accidents, including failure analysis and testing.

Jeffrey D. Rupp, MSE – Engineering Associate Mr. Rupp has a BS in mechanical engineering from the University of Michigan and a MS in systems engineering and engineering management from Wayne State University. Among his company affiliates is 26 years with Ford Motor Company and Volvo Car Corporation, where he was involved in crash development and crash sensing calibrations.

LECS (UK) Limited  is an International Engineering Firm specializing in Lifts, Escalators, Facade Access and Funiculars (cable cars). With over 20 years of trading history, their specialized engineers are qualified, experienced and carry full professional insurances. Members of the engineering team have all worked for major contractors and have held positions including Senior Engineer, Project Manager and Commissioning / Test Engineers. As a result, LECS has over 150 years of accumulated experience within the key staff of the engineering team and currently employs 10% of the world’s graduates of the MSc in Lift Engineering from the University of Northampton.

LECS (UK) Limited is a member of independent bodies such as ACE, BSI and ConstructionLine. They have an accredited Quality Assurance scheme to ISO 9001 (2008) and are regularly audited. They provide services for many market sectors including overseas projects, hotels, retail, commercial health, local authority and heritage. The engineers at LECS (UK) have extensive experience as Expert Witnesses and Consultants in litigation involving lifts and escalators. Their services include preparing expert reports in accordance with Regulation 35 of the Civil Procedure Rules and also in Criminal cases. They are also available for adjudication and arbitration cases. LECS (UK) expert witness services have been called on in overseas situations including Gran Canaria, Dubai, Hong Kong, Spain and Turkey.

Services Include:

• Expert Witness - Litigation Support
• Statutory Inspections
• Maintenance Audits
• Acquisition & Condition Surveys
• Project Management
• Traffic Analysis
• Risk Assessments
• New Installations & Modernization Specifications
• Maintenance Specifications
• Training
• Portfolio Management

John L. Ryan, BSME, P.E. is a Mechanical Engineer who provides general Mechanical and Structural Engineering expertise. Mechanical and Safety Engineering (MASE) provides full service analysis and accident reconstruction of products involved in accidents. 

Mr. Ryan's services have been requested for attorneys and insurance companies needing forensic engineering expert witness testimony to determine whether machinery and products involved in injury cases were adequately designed or whether they have a Design, Manufacturing, or Material Defect. All products are lab-tested on site to determine adherence to industry standards and engineering design protocol. Alternate preventative designs are developed when none exist commercially. 

Mr. Ryan is available for both Plaintiff and Defense, depending on the individual case. His services include producing high quality reports and visual aids in the courtroom such as scale models to help explain accident scenarios and alternate designs to judges and juries. 

Areas of Expertise:

• Accident Investigation and Reconstruction
• Machine Guarding Accident Investigation
• Climbing Gym Accidents
• Belay Device Failure
• Rock Climbing Accidents
• Fall Protection Failures
• Ladder Failure Investigation
• Design Defect Analysis
• Structural Analysis of Buildings
• Product Liability Investigations
• General Engineering Injuries and Issues
• Industrial safety
• Engineering Continuing Education
• Product Certification

View John Ryan's Consulting Profile.

Page Engineering is a professional consulting firm that combines Ergonomics, Industrial Engineering, and Health and Safety expertise. They have served industry leaders in the areas of Transportation, Shipping, Manufacturing, and Health Care throughout the United States and Canada. Established in 1994, their approach is bolstered by years of litigation scrutiny and backed by extensive application of ergonomics, human factors, epidemiologic, and occupational medical scientific literature. They specialize in human factors and ergonomics assessments, including both acute and cumulative exposures and their hands-on approach is backed by extensive research and measurement of actual work exposure to occupational physical factors and workplace design.

Litigation Support - The professionals at Page Engineering provide forensic engineering and root cause analysis expert witness services to counsel representing both Plaintiff and Defense. Their areas of expertise include:

Ergonomics Human factors Musculoskeletal Injury Biomedical Injury Analysis Biomechanical Injury Analysis Health and Safety Industrial Hygiene Physical Demands Assessments

Usability Testing Occupational Accident Reconstruction Biomechanical Modeling Vibration Measurement Compliance Occupational Risk Management Return to Work Regulatory and Consensus Standard Initiatives

George B. Page, CPE, is a Certified Professional Ergonomist. Since founding Page Engineering, Mr. Page has been providing ergonomics services, integrating multiple disciplines (industrial engineering, safety, health, business, regulatory) to provide effective results, whether in the application of job analyses and job improvement processes or in physical job demands analyses. His experience includes conducting ergonomics analyses and research in the railroad industry, primarily, and in heavy industry, in general, for over 30 years. Clients include Union Pacific Railroad, Kansas City Southern Railways, Association of American Railroads, FedEx, American Petroleum Institute, Food Marketing Institute, Food Distributors International, Blue Water Bridge Authority, USPS. His expertise includes job exposure assessments, physical demands assessments, accident reconstruction, and forensic engineering.

Greg G. Weames, CPE, CCPE, CRSP, is a Certified Professional Ergonomist who provides forensic services regarding Musculoskeletal Injury / Disorder Risk and expert testimony. Since joining Page Engineering, Inc., Mr. Weames has been asked to provide consulting services in ergonomics for over 500 cases involving civil lawsuit work-related injury/disorder claims. With training, education, and experience in musculoskeletal injury and musculoskeletal disorder as a focus, he applies generally accepted methodology in his analysis of causation to a reasonable degree of scientific certainty. Mr. Weames has his expert witness experience from within the railroad industry, which includes transportation, construction maintenance, mechanical shop, communications, and office environments that support a large variety of jobs and work tasks. Over the past 20 years of providing expert witness services, Mr. Weames has relied on independent, objective measurements of claimed exposures to occupational physical factors and the epidemiologic scientific literature, relevant ergonomics guidelines, and standards to support his opinions. Mr. Weames has given depositions and has appeared at jury trials in both State and Federal US courts during his years doing expert witness work.

Stephen D. Fleming, CPE, CXLT, is an Industrial Engineer / Ergonomist whose background includes analyzing work environments and work tasks using industrial engineering work measurement methods and risk assessment models for different body regions. His expertise is in assisting industrial clients in applying ergonomics to workplace processes, tools, and equipment, including all major North American railroads, FedEx, Ford Motor Company, Lear Seating, USPS, and the Blue Water Bridge Authority. Mr. Fleming has been acknowledged for developing and implementing a methodology for measuring and analyzing exposure to whole-body vibration (WBV) and hand-arm vibration (HAV).

View Page Engineering's Consulting Profile.