Construction Accounting and Costs Expert Witnesses: 17

Jeffrey Phillip Weinstein, AIA, a California licensed Architect since 1982, with Masters Degree in Real Estate Development from USC, has been involved in the development, design and construction of office buildings, high-rise condominiums, multi-family residential podium-type projects, retail, neighborhood shopping centers and regional malls, hotels and resorts, hospitals, and schools (K-12 and University).

Expert in real estate development, government approvals, entitlements & permits, architect's standard of care, construction management, claims & defects, A/E/C agreements. Expertise includes building envelope & water intrusion, zoning & building codes, errors/omissions, destructive testing & repair, schools (DSA), hospitals (OSHPD), condominiums, commercial/retail/mixed-use projects, high-rise structures, hotels & resorts. Previous employers include Nadel and Callison Architects, Tishman Construction, Trammel Crow Company, Kaiser Permanente, and California State University.

Professional Licenses / Certifications / Affiliations:

• California Registered Architect, License #12822
• Member, American Institute of Architects, Urban Land Institute, Construction Specification Institute, and Society for Marketing Professional Services
• Member, North Santa Barbara County Board of Architectural Review

Litigation Support: Jeffrey Weinstein has been retained as an expert witness as Owner's Representative, Construction Manager, Contract Administrator, Project Manager and Architect by Developers, Builders, Institutional Owners (Hospitals & Schools), Municipalities, and Corporate Clients. Mr. Weinstein provides professional Architectural and Construction Expert Witness opinion, testimony and services on matters, such as:

Architectural Forensic Architectural Construction Management Building Code Requirements Construction Industry Standards Professional Standard of Care Design Defects, Errors & Omissions

Construction Defects & Failures Architectural Practice & Peer Review Construction Claim Evaluation Change Order Analysis & Cost Overruns Zoning Entitlements, Land-Use, and Permitting Project Delivery - Fast-Track, Design-Build, GMP Design & Construction Accident Claims

View Jeffrey P. Weinstein's Consulting Profile.

James D. Wamble, PE, RLS has over 40 years of experience as a Professional Civil Engineer and Registered Land Surveyor. During the course of his career, Mr. Wamble has worked on land planning, land surveying, or civil engineering projects in all counties of the middle and west Tennessee regions, and several counties in east Tennessee. Mr. Wamble has offered litigation support services as an expert witness in cases since 1976. In the last four years, he has testified 10 times in 7 lawsuits. These litigation cases include land planning, land surveying, and civil engineering issues. Mr. Wamble has experience with depositions, trials, hearings, and arbitrations.

Expert Witness Services Include:

Research Site Inspections Engineering Analysis Land Surveys

Survey and Civil Engineering Drawings Investigation Report Writing Exhibit Preparation

Areas of Expertise:

• Civil Engineering: Design of grading, drainage, utilities, roads, lakes, dams, detention basins, parking lots, shopping centers, subdivisions, apartments, condominiums, planned unit developments, specific plans, industrial parks, mobile home parks, mini warehouses, hotels and office building site plans; flood, drainage, and utility studies; low impact design; financial developability and constructability analysis of proposed developments; preparation of cost estimates; assisting clients in setting project budgets; designing projects to contain cost within determined project budget; construction project management, inspection, administration, and processing of contractors’ pay requests
• Land Surveying: Topographic, Route, Land, Boundary, Utilities, Aerial ground control, Engineering design, and Construction Surveys
• Land Planning: Land use/development feasibility analysis, planning and concept design of residential, commercial, industrial and municipal projects; zone change applications; planned unit development and specific plan applications; site selection consultation; and graphic presentations

View James Wamble's Consulting Profile.

Robert (Bob) Ryan, PhD, PE, is a Senior Estimator with Heavy Civil Construction experience including bridge / structures, paving, foundations, marine, and grading work. He has over 15 years of experience working within the construction industry, primarily in operations and estimating. He has completed projects totaling more than $2 billion, and was directly involved in multiple projects receiving national merit.  

Bob has led projects involving bridges, roads, marine structures, rail, tunnels, airports, and light industrial. His project management experience has led to the development and deep understanding of schedules, standardized cost estimating approaches, subcontractor management, contracts, procurement, project completion, and Disadvantaged Business Enterprise (DBE) programs compliance issues.

Litigation Support -  Working as a contractor, engineer / consultant, and owner in the heavy-highway sector gives Bob the ability to see all sides of complex contractual issues. He has been involved in cost escalation claims and economic impact analysis related to volatile market conditions. He has experience working on large, complex heavy highway projects and has the skills and knowledge necessary to provide expert testimony in these cases.

Bob has advised attorneys for both plaintiff and defendant, and executive levels of DOTs and contractors alike. He has led and supported expert analysis on claims exceeding $100 million.

 Areas of Expertise:

Dispute Resolution Disadvantaged Business Enterprise (DBE) Issues Good Faith Effort (GFE) Claims Contract Issues Cost Estimating Contractor Performance

Contractor Means and Methods Construction Planning and Scheduling Construction Defects Forensic Schedule Analysis Financial Damages Preparation and Evaluation Code Compliance

Background Experience - Bob’s professional roles have included project controls, field engineering, superintendence, project management, and estimating. In his 10 years as a contractor, he held roles from field operations to estimating. As a consultant, he managed projects ranging from $1M to $300M. As an owner’s representative Bob was responsible for complete cost estimates averaging $2B. Bob is currently a faculty member at Oregon State University in their Construction Engineering Management program. 

Bob has successfully balanced completing his multiple degrees while exceeding goals as a full-time professional. His dissertation involved economic analysis of cost variance for over 12,000 projects. His coursework was a blend of project management, civil engineering, accounting, economics, and statistics. He is experienced in a wide variety of alternative delivery methods such as design-build, public-private- partnerships (P3) accelerated bridge construction, job order contracting, and negotiated lump sum.

Mark E. Rieser, II, MS, PE, AIA, GBC, GEC has over 30 years of experience in the Engineering, Architectural, Construction, and Building Design industry. He provides his clients with a comprehensive knowledge of Engineering, Construction Technology and Construction Standards of Professional Practice. 

Background Experience - President of an “active” Design and Building company with a professional staff and Headquarter offices in San Jose and Los Angeles, and offices in Sacramento and San Francisco. Mr. Rieser has managed, designed, and constructed over 4,000 units to include high-rise, single family homes, condominiums, townhomes, podiums, apartments, and commercial buildings, His experience includes building and roadway design, construction, management, with designs of over 500 miles of asphalt and roadway improvements, tunnels, San Francisco Airport, Santa Clara Light Rail, Southern Pacific Railroad, Caltrans, and BART. 

Mr. Rieser has an insightful understanding of Civil / Structural Engineering, Soil Engineering, Transportation, Traffic Engineering, Hydraulic Engineering, Safety Expert, OSHA Standards, Architectural Design, Asphalt Design, Cost Estimation, Public Works Design Bidding and Estimation, General Engineering, General Building, and an Accident Reconstruction expert. “Our bids are not just a tool but are numbers that we be use to finish the work, accurately, on-time, and safely.” 

Forensic Construction and Engineering - Mark Rieser is a renowned forensic expert with the knowledge to safeguard clients from unwanted litigation as well as support both plaintiffs and defendants. He works closely with insurance companies and attorneys on various public, city, and state cases throughout the western United States. To date, he has been designated as an expert in over 550 Forensic Construction and Engineering cases throughout the United States. Mr. Rieser has been designated and testified Court as an expert in the following categories:

Traffic Engineer Transportation Engineer Architect Safety Expert General Building Contractor Civil Engineer General Engineering Contractor Roofing

Estimator Soils Caltrans Standards Structural analysis Hydraulics OSHA Standards Construction Management Waterproofing

NorCal Headquarters San Jose Office 2033 Gateway Pl Suite 500 San Jose, CA 95110	San Francisco Office 425 Market St Suite 2200 San Francisco, CA 94105	SoCal Headquarters Los Angeles Office 10100 Santa Monica Blvd. Suite 300 Los Angeles, CA 90067	Sacramento Office 777 Campus Commons Rd Suite 200 Sacramento, CA 95825

View Mark Rieser's Consulting Profile.

Florida Office:
Andrew Avalon, PE, PSP
Chairman & CEO
8633 Willow Kane Court
Orlando, FL 32835
aavalon@long-intl.com
T: (407) 445-0825     F: (407) 650-3399

---

Long International provides expert engineering and construction claims analysis, expert testimony, project management consulting, and insurance claims analysis services. We focus on projects in the following industries: building and construction; gas, gasification, GTL, LNG, and NGL; industrial and manufacturing; mineral and mineral processing; offshore oil and gas; oil sands; pipelines and utilities; power; refineries, petrochemical, and chemical; transportation; and water, wastewater, dams, and marine. We analyze claims, not limited to, disputed change orders, schedule delay, acceleration, time extensions, liquidated damages, loss of productivity, defective specifications, and deficient project management performance.

Richard J. Long, P.E., P.Eng., Founder of Long International, has over 50 years of U.S. and international consulting experience involving construction contract disputes analysis and resolution, arbitration/litigation support and expert testimony, project management, engineering/construction management, cost and schedule control, and process engineering. As an internationally recognized expert in the analysis and resolution of complex construction disputes for over 35 years, Mr. Long has served as the lead expert on over 300 projects having claims ranging in size from US$100,000 to over US$2 billion. He has presented and published numerous articles on claims analysis, entitlement issues, CPM schedule and damages analyses, cumulative impact claims, and claims prevention.

Rod C. Carter, CCP, PSP is President of Long International and has over 20 years of experience in construction project controls, contract disputes and resolution, negotiations, mediation, arbitration support, and expert testimony on scheduling, loss of productivity, and quantum issues.  He has experience in entitlement, schedule, and damages analyses on over 30 construction disputes ranging in value from US$100,000 to US$7 billion, related to oil and gas, oil refinery, LNG, heavy civil, nuclear, environmental, chemical, power, industrial, commercial, and residential construction projects. Mr. Carter specializes in loss of productivity, cumulative impact, and quantum calculations, and had a lead role in assessing damages on more than a dozen major disputes.  In addition, Mr. Carter has developed cost and schedule risk analysis models using Monte Carlo simulations to address the uncertainty of estimates and claims.

Scott M. Francis, P.E., PSP is a Vice President of Long International and has over 20 years of experience in project management, contract disputes analysis and resolution, CPM schedule preparation, execution, and analysis, productivity analysis, contract administration, design engineering, construction management, and government contracting.  He provides schedule development and assurance services, cost estimating, and claims analysis services on projects for both owners and contractors.  Specific responsibilities include CPM development and reviews, CPM schedule delay and acceleration analyses, change order impact analysis, issue identification, correlation of impacts to schedule activities, and productivity evaluations.

Daniel D. Bawden, GMB, CAPS, CGR, CGP, JD, has over 35 years of experience in the Construction Industry. He is a Graduate Master Builder, Certified Graduate Remodeler, Certified Aging in Place Specialist, and a Certified Green Building Professional.

Mr. Bawden serves as an accredited Instructor for the National Association of Home Builders, certifying other builders in his own specialties. He earned both his Bachelor’s degree and Law degree from Baylor University. He is currently serving as Vice Chair of the NAHB Remodelers Council, on track to be the national spokesman for the remodeling industry in 2017.

Litigation Support - Mr. Bawden has an outstanding reputation for winning cases. His combination of legal and hands-on construction experience, along with his numerous certifications, make him a highly credible witness in all facets of residential construction.

Mr. Bawden helped write the "Residential Construction Performance Guidelines," which is the primary criteria for construction standards. With trial experience on behalf of both homeowners and builders, Mr. Bawden is a likeable persona, an excellent and clear communicator, effective before arbitrators, judges, and juries alike.

Areas of Expertise:

Construction Cost Estimates / Analysis Construction Defects Project Management Disputes

Construction for the Disabled (ADA) Construction Delays Code Compliance / Violation

View Dan Bawden's Consulting Profile.

Rudolph P. Frizzi, PE, GE, D.GE is a Civil Engineer with over 25 years of extensive practical Foundation and Geotechnical Engineering experience. Mr. Frizzi has extensive project management experience throughout the United States and internationally, with particular emphasis on:

• Foundation Design and Construction in Urban Areas
• Large Scale Land and Waterfront Public and Private Development Projects

Mr. Frizzi has obtained extensive field, office supervision, and project management experience including soil and rock sampling and in-situ testing; monitoring pre , during, and post-construction with state-of-the-art geotechnical instrumentation; nondestructive testing; aqueous and sub-aqueous inspections and investigations; and heavy construction which has contributed to his practical approach to geotechnical problem solving. In addition to his "engineer of record" experience, Mr. Frizzi has provided expert geotechnical consultation and trial testimony on over 50 excavation and foundation litigation cases throughout the United States and internationally. His services are available to attorneys for Plaintiff and Defense.

Areas of Forensic Expertise:

• Foundations for Stadiums, Arenas, High-Rise Structures in Urban Areas
• Embankment and Dam Stability
• Large-scale Land and Waterfront / Marine Structures and Development
• Shallow and Deep Foundation Systems
• Soft and Hard Rock Treatment
• Earthwork
• Ground Improvement of Waste Fills
• Temporary and Permanent Lateral Support Systems for Deep Excavations
• Geotechnical Instrumentation and Vibration Monitoring
• Construction Dewatering

View Rudolph Frizzi's Consulting Profile.

Prof. Makarand (Mark) Hastak, PhD, PE, CCP, CRIS, is the Professor and the Dernlan Family Head of Construction Engineering and Management as well as Professor of Civil Engineering at Purdue University. Dr. Hastak has been involved with the construction industry for the past 35 years providing his expertise through consulting, research, teaching, and service to the industry. 

Dr. Hastak is a world renowned expert in the area of construction engineering and management including risk management, profitability of Construction companies, process improvement, disaster risk reduction, resilience and capacity building, infrastructure management, intelligent planning for the built environment, project control, project management decision-making, and strategic planning. As a Fellow of the American Council on Education (cohort of 2013-14) at Cornell University his work focused on the various facets of Hybrid RCM budget, engaged institution, and Public-Private Partnership in academia.

Dr. Hastak is a Professional Engineer (PE), a Construction Risk Insurance Specialist (CRIS), and a Certified Cost Professional (CCP). He  has worked on numerous projects sponsored by the Construction Industry Institute (CII), NSF, State DOTs, and City Agencies. He is the current President of CIB (International Council for Research and Innovation in Building and Construction) and the Chair of the Advisory Board of teh Global Leadership Forum for Construction Engineering and Management programs (GLF-CEM). He also serves as an Academic Advisor to the Downstream and Chemicals Committee of the Construction Industry Institute (CII).

Dr. Hastak  has authored over 200 publications in his areas of expertise. He has co-authored a widely used book on Infrastructure Planning, Engineering, and Economics (McGraw-Hill 2006 and 2015). Dr. Hastak served on the Education Board of the Association for Advancement of Cost Engineering (2004-2016). He was Editor for two AACE books, the Skills and Knowledge of Cost Engineering (6th Ed. 2015) and the CCP Certification Study Guide (2nd Ed. 2016). He was also the Editor-in-Chief of the ASCE Journal of Management in Engineering (2009-2016). 

Dr. Hastak has given over 50 keynotes and invited lectures around the world. As a prominent educator and consultant, he also engages in developing training material and workshops as well as regularly teaching professional courses for the A/E/C industry. His services include consultation, on-site investigation, data collection, assessment, and reporting. He has completed the 30-Hour OSHA Hazard Recognition Training for the Construction Industry 

Dr. Hastak Lectures at the 2015 International Conference on Building Resilience

Litigation Support - Dr. Hastak offers expert witness services to attorneys representing both plaintiff and defendant. He has served as an Expert Witness on twenty-six (26) cases since 2017 and was deposed on eight plus two evidence depositions. His services include case reviews, written reports, depositions, and trial testimony as needed. 

Areas of Expertise:

Construction Engineering Construction Management Cost Overruns Schedule Delays Construction Safety/OSHA Modular Construction Patent Infringement

Factory Built Construction Infrastructure Planning Data Center Construction Project Risk Management Disaster Recovery / Disaster Mitigation Trade Secrets Misappropriation Contracts & Warranties

View Dr. Hastak's Consulting Profile.

David Morris has over 30 years of deep understanding and hands on experience of Construction and Construction Processes that give him a unique perspective in the industry. Having worked in many roles, Mr. Morris has the ability to formulate conclusions based on practical experience. Staying abreast of new technologies, he is able to apply them to outdated construction processes.

Mr. Morris has welding certifications in nearly all processes (MIG, TIG, Stick) and most materials, (Carbon Steel, Various grades of Stainless Steel, Aluminum, Chrome,). He has extensive experience in Instrumentation, Controls, Building automation Systems, HVAC, Refrigeration, Plumbing Codes and Design, Drafting and Detailing, layout and quantity take-off, medical gas installation, Plumbing and Piping Detailing, Computer Aided Drafting, and BIM

Litigation Support - Mr. Morris serves as an expert witness for attorneys representing both plaintiff and defendant. His services include onsite inspection, thorough reporting, depositions and trial testimony as needed. Cases include:

Construction Scheduling Root Cause Analysis Construction Defects and Delays Planning, Designing, Managing Construction

Mechanical, Electrical, Plumbing Coordination (MEP) Building Information Modelling (BIM) Computer Aided Drafting Initial Design, Construction, Operations, Maintenance

Select Background Experience:

• Prior to founding DMorris.consulting, Mr. Morris served as Director of Virtual Construction for EMCOR Construction Services from 2008-2016. In this role, he directed the virtual construction activities and operations of 82 EMCOR companies. His scope of work included drafting contract language for BIM and pre-construction, setting up new projects in lean and BIM delivery methods, and reviewing new construction technologies among other duties, Managing 3D and BIM processes
• From 2001-2008, Mr. Morris worked with University Mechanical and Engineering Contractors as Director of Virtual Construction. He was responsible for estimating Plumbing, HVAC Piping and Process Piping for numerous research laboratories and healthcare facilities valued at over 100mm + each. He also delivered conceptual estimates for numerous Biotech, Power, and Co-Generation plants.
• Select Project Participation: San Joaquin County Hospital, City of Gilroy Waste Water Reclamation Plant, Shafter Prison, Vandenberg Air Force Base HVAC Replacement, Space Shuttle Launch Complex Project, Tehachapi State Prison Level-4 High Security Prison Housing, Cal Poly San Luis Obispo Co-Gen Facility, Kern Medical Center New Hospital Wing Expansion, Anheuser Busch Yeast Plant Expansion, and multiple Piping, Petrochemical, Hospital, and School projects.

*This Mechanical, Electrical, Plumbing, and Fire Protection Systems (MEP) Spatial Coordination Requirements for Construction Installation Models and Deliverables is a derivative work of a best practice guideline written by David Morris in 2003 and modified for the AGC BIMForum in 2009. It is the result of capturing ten years of practical methods on real world construction projects and reflects continual feedback and improvement gained from that process.

View Dmorris.consulting's Business Consulting Profile.

David M. Bekus has over 40 years in the Construction Industry specializing in new home construction, and remodeling. Mr. Bekus has been a project manager, overseeing all aspects of construction from conception and approvals to final sales for single homes and developments. Mr. Bekus is licensed by the State of New Jersey as a building inspector (RCS, ICS, and HHS), a licensed home remodeler, and a licensed new home builder. He is also certified in Project Management, Cost Estimating, Construction Methods, Construction Site Safety, and is a EPA Lead Safe Certified Contractor. Litigation Support - As a seasoned expert in the construction field, Mr. Bekus provides comprehensive reports  and credible expert witness testimony. His services include project evaluations, building code inspections, and clear precisely written reports. Mr. Bekus' expertise is available to counsel representing both Plaintiff and Defendant and has testified in NJ superior court Areas of Expertise:

Industry Standards Building Code Compliance, Specifications Contract and Plan Specifications New Construction Defects Roof Issues Water Issues

Framing Defects Siding Defects Concrete Defects Insurance Claims Poor Workmanship Home Owner Association Issues

View David Bekus' Consulting Profile.

Brian H. Aanestad has over 30 years of Construction and Fleet experience, including Heavy Equipment, Truck, and Trailer Transport. He currently serves as President and Construction Consultant at Inland Valley Engineering, Inc. and as an Expert Witness for Discover Experts.

Mr. Aanestad is a Consultant and Expert witness for matters including Underground Construction and Placement of Underground Utilities. He has decades of experience overseeing the placement of underground utilities, pipelines, and conduit. In addition, he has almost 20 years of experience in the Full-Service Truck Leasing industry, overseeing transportation, logistics, leasing, rental, and maintenance activities. His company was honored for its work on the Scripps Seawater Return Lines at the University of California, San Diego. The complex, $2.5 million project included nearly 4,500 feet of piping.

Litigation Support - Mr. Aanestad provides expert services to attorneys representing plaintiff and defendant which include on-site review, written reports, depositions, mediation, and trial testimony as needed. Most cases end in mediation or negotiated settlement.

Clients have included such firms as Heffernan & Boortz LLP, Wood Smith Henning & Berman LLP, Rutan & Tucker LLP, and Dowling/ Aaron, Chancio Brown LLC., Southern California Edison, Vast Networks (CVIN), City of Kansas City Missouri, and the City of Oceanside.  

Areas of Expertise:

Underground Trenchless Public Utilities Fiber Optics Installation   Engineering Contractor Negligence Feasibility Studies Underground Utility Easements Construction Standard of Care Construction Defects, Delays, Change Orders Construction Dispute Resolution Construction Damages / Cost Analysis Construction Equipment / Pipelines Heavy Trucks and Trailers

Forklifts Cranes Skip Loaders Backhoes Excavators Drilling & Boring Machines Horizontal Directional Drills Hydraulic Moles Truck Leasing, Rental, Maintenance Transportation Logistics DOT / BIT Review

Steven M. Murow has over 45 years of experience in the Land Development and Construction industry with expertise in Earthmoving, Site Development, Street Improvements, and Underground Utilities. 

During that time, Mr. Murow has served as a principal in two leading contracting firms; consultant to major land developers; specifier and bid administrator; senior project manager, and as an expert witness. 

Litigation Support - Over the past 20 years, Mr. Murow has supported developers, municipalities, builders, and contractors through their legal teams. He has a perspective on general engineering contracting unmatched by opposing experts in the field having been involved in the bidding of over 2,000 projects since 1978 and managing over 300 of those projects in the mass grading and site development arena as a principal owner of the firm. Mr. Murow has been deposed 70 times and testified in trial / arbitration 34 times. His expertise has been called upon in Dallas, Texas, Conway, Ark. and throughout California.

Areas of Expertise:

Public Engineering and Building Contracting Private Engineering and Building Contracting Earthmoving Site Development Street Improvements Underground Utilities  Land Development Pro Formas

Bidding Cost Estimating Change Orders and Billing Contractors, Inspector, Manager Standard of Care  Claims Mitigation Scheduling Cost for Abandonment / Termination Dates

"DIRT, not civil engineering or geotechnical, but as a general engineering contractor performing the work and as a Construction Manager managing the work on projects up to 1,200 Acres and $50,000,000 in value. I can tell you how it was bid, should have been bid, where it went wrong, and cost to repair." - Steven M. Murow

Sanford C. Loy , CCM, B.Arch, MSCE, has over 40 years of experience in the Construction Industry. Mr. Loy has Degrees in Architecture and Engineering. A Certified Construction Manager (CCM), he is committed to the Code of Ethics and Standards of Professional Practice established by the Construction Management Association of America. CCM is the ANSI accredited professional designation for construction management and is the gold standard for CM service providers in over 145 countries.

Background Experience - Mr. Loy's experience spans virtually every type of building and design process. His strength centers on his understanding of the dynamics and interactions of the various trades and professions unique to every building project. He has experience with Construction Management at Risk, Construction Management Agency, Design-build, and Design-bid-build. Having successfully managed the completion of over one billion dollars of construction, Mr. Loy served as a Regional Engineer for the American Institute of Steel Construction and as Director of Construction and Development for Belz Enterprises, the largest development company in Tennessee, before founding Construction Strategies in 1988.

Litigation Support - Mr. Loy provides Construction Claim and Dispute Analysis services, with special expertise in Concrete Design and Design-Build. Having been a teacher of many of the principles and processes used in the industry he knows how to explain the difficult technical aspects of the information and analysis in a way which makes the facts understandable and believable to opposing counsel, insurance companies, judges, and juries. Mr. Loy has experience and provides assistance with various dispute resolution approaches, such as Owner / Contractor dispute resolution boards, arbitration, mediation, and provides expert witness testimony if necessary.

See services offered at https://www.construction-strategies.com/what-we-do 

View Sanford Loy's Consulting Profile.

Michael A. Pollock, PE, USPTO, is a Mechanical Engineer responsible for the design and engineering of commercial, industrial, manufacturing, institutional, and residential venues, as well as efforts relating to services and products used in and around these facilities. Mr. Pollock's full CV can be viewed at cogentexpert.com.

Business and industries include electronics, safety and construction, building materials, polymers and plastics, instrumentation manufacturing, petrochemicals, chemicals, pharmaceuticals, colleges, athletic facilities, textiles, coatings and resins, food storage, biosciences, supermarkets, inks & pigments, automotive, facility and real estate operations, agricultural, transportation, nuclear, healthcare, nutrition, retail, distributors, pulp and paper, packaging, utilities, apparel, and R&D centers.

Litigation Support - Mr. Pollock is a subject matter expert in Commercial and Industrial Engineering Applications and Projects, as well as engineering standards and applicable codes (ASHRAE, ASME, NIST, NFPA, NBIC, ASTM, SAE, LEED, ASCE, GMP, ISA, BOCA, and EPA Regulations.) He has engaged with local, state, and governmental officials and agencies regarding numerous matters over his commensurate years of experience.

Areas of Expertise:

Investment Engineering Economics Mechanical Engineering Standard of Care Architectural Standard of Care Construction Delay Construction Defect Construction Schedule Analysis Accident Analysis Metallurgical Failure Rotating Equipment Electrical Failure Chemical Failure Processes Instrumentation and Controls

Chillers Coatings Refrigeration Thermodynamics Water Treatment Steam Systems and Boilers   Power and Utilities Energy Conservation Environmental Impact Safety HVAC Project Management Product Development

Registrations

• Professional Engineer: PA (PE075410)
• American Bar Association (ABA) – Construction Forum
• Environmental Protection Agency (EPA) Clean Air Act Certification – Universal (includes Chillers, HVAC & Refrigeration)
• United States Patent & Trademark Office Registered (USPTO)                              

Forensic Consulting Experience

Warehouse Distribution Facility – Maryland - Evaluated a $10M (million) claim relating to purported construction defect claims by the 600,000 sq. ft. facility owner against the facility construction contractor and an original equipment manufacturer relating to installed infrastructure in the facility. Developed an expert opinion and expert report regarding the analysis of the purported defects and a proposed repair solution to correct said defects. 

 Psychiatric Hospital Facility – North Carolina – Evaluated a $28M (million) construction claim by the general contractor against a hospital facility concerning a $100M facility construction project.  Developed an expert opinion and report for general construction issues, constructability, design revisions, and corresponding delay analysis for mechanical, HVAC, electrical, smoke and fire, structural, security and building automation systems. 

Forensics Consulting Work-in-Progress 

• 2022 – International Trade Commission (ITC) Matter – Resin Manufacturing Facility Construction Delay / Completeness Analysis
• 2022 – Mechanical Systems Coatings Matter Analysis
• 2021 – Industrial Manufacturing Facility Standard of Care Matter, Construction Defect, Construction Delay     
• 2021 – Electrical Distribution System Construction Defect Matter, Standard of Care
• 2021 – Hotel Facility HVAC Materials of Construction Related Defect Matter

Since 2010, Craig Moskowitz, MBA, MS, PE, the President and Managing Member of CLM Engineering Associates, LLC (CLM), has been concentrating the comapny's focus on forensic engineering/expert witness work for the insurance industry and legal community. In addition, they offer construction management, civil engineering and building inspection services. 

CLM has extensive construction management experience on both commercial and residential projects. Projects have included:

•  Safety inspections on both civilian and military projects through application of OSHA regulations. Designed drainage systems for the government while an officer with the United States military. Cost estimating for various projects exceeding $500 million<li>
• Designed document creation and management of high-rise construction in Manhattan
• Management of telecommunications projects for Verizon in Manhattan including CPM schedule creation and updating
• Directed and managed all water distribution system and sewer system work while working as a contractor to the New York City Department of Design and Construction. 
• Marketplace Services

Litigation Support - Forensic work related to evaluation of structural steel systems with commercial building construction and insurance-related claims due to storm damage on commercial and residential structures. Craig Moskowitz has been deposed several times in litigation matters. Mr. Moskowitz has testified 17 times in the past four years. 

View Craig Moskowitz's Consulting Profile.