Acceleration Claims on Engineering and Construction Projects

By: Long International, Inc. - Richard Long P.E.
Tel: (303) 972-2443
Email:Long International, Inc.

View Profile on Experts.com.

1. INTRODUCTION

Time is money especially on engineering and construction projects. Because delays in the completion of the project usually result in increased owner, engineer, and contractor costs, the overall time of performance is vital to the financial success of the project. The importance of time is evidenced by the significant role played by CPM schedules, completion dates, and milestones in the bidding and awarding of engineering and construction contracts. The desire to minimize costs and the time of performance often causes the occurrence of acceleration.

This article discusses the following topics:¹

Types of Acceleration;
Key Elements of Acceleration Required by the Courts;
Acceleration Claims Outside of the United States;
Notice Requirements;
The Relevance of the Date When the Time Extension Is Given;
Contract Provisions Associated with Acceleration;
The Effect of a "No Damage For Delay" Clause on Acceleration;
Identifying Acceleration Using the Project Schedules;
Documenting Acceleration Evidence; and
Acceleration Damages.

2. TYPES OF ACCELERATION

There are three types of acceleration: directed acceleration, constructive acceleration, and voluntary acceleration.

Directed acceleration occurs when the owner or construction manager issues a specific order to its construction contractor under the contract provisions to 1) complete the project earlier than the originally scheduled completion date, 2) re-sequence the work and/or utilize overtime, additional shifts, and/or extra engineering or construction labor, supervision, or equipment to complete the base contract work plus additional or changed work within the original contract time,² or 3) re-sequence the work and/or utilize overtime, additional shifts, and/or extra engineering or construction labor, supervision, or equipment to make-up for contractor-caused delays that threaten the on-time completion of the project. These measures can result in costs being incurred that would not otherwise have been required.

. . .Continue to read rest of article (PDF).

Long International provides expert claims analysis, dispute resolution, and project management services to the Process Plant Engineering and Construction industry worldwide. Our primary focus is on petroleum refining, petrochemical, chemical, oil and gas production, mining/mineral processing, power, cogeneration, and other process plant and industrial projects. We also have extensive experience in hospital, commercial and industrial building, pipeline, wastewater, highway and transit, heavy civil, microchip manufacturing, and airport projects.

DO NOT REPRODUCE WITHOUT WRITTEN PERMISSION BY AUTHOR.

12/11/2015· Construction

Modular Cabinet Systems Retail Store Fixtures: Injuries from Improper Installation

By: Michael Panish

I have been the retained expert witness by both the plaintiff and defendant to determine the causes of a variety of significant injuries that have happened as a result of improper cabinet and millwork installation practices. In most claims, if product abuse or deferred condition was not the reason for the injury, poor installation practices that have omitted required hardware was to blame. Architectural millwork injuries have occurred repeatedly in shopping centers and malls, hotels, hospitals, airports, and offices throughout the country. Casinos and restaurants are also routinely the location of significant cabinetry related failures leading to serious injuries. Many offices and industrial buildings that utilize modular furniture have had employees injured by improper or completely unattached components. In my other articles, improperly attached architectural millwork has been discussed. Heavy mirrors and headwalls have fallen upon hotel guests while they were asleep in bed. Generally, these failures occur due to lack of appropriate fasteners, missed structural connections, or product tampering.

3/11/2024· Construction

Apportionment Of Indirect Costs To Significant Change Events

By: Long International

This article discusses the methods, concerns, and considerations for apportioning indirect costs in a dispute setting where the apportionment of indirect costs is necessary and when detailed actual indirect costs or indirect labor hour data assigned specifically to the underlying change that is being analyzed does not exist in the contemporaneous project records.

10/14/2022· Construction

The "No Damages For Delay" Clause

By: Long International

Construction projects involve risks. A well-structured construction contract allocates certain risks to the party that is best able to control those risks. Delay is a common risk that construction contracts allocate. A delay may increase costs for owners, contractors, and subcontractors to complete a project.

;

articles

Acceleration Claims on Engineering and Construction Projects

1. INTRODUCTION

2. TYPES OF ACCELERATION

Related articles

Follow us

SECTIONS

ABOUT US

CONTACT US

LEGAL